Public tenders for environment in Opole Poland

Find all Environment tenders in the world.
Finding business opportunities has never been easier.

Results for environment. Make a new search!

Sewage, refuse, cleaning and environmental services

Miejski Zarząd Dróg w Opolu | Published March 9, 2017  -  Deadline April 18, 2017
cpvs
90000000

The purpose of this call for tenders is to conclude a framework agreement with a single operator for the period of time specified in Section 8 Terms of Reference, separately for each part.

That contract was divided into 2 parts:

Region 1 includes the area of ​​Opole-Downtown, Wójtowa village, Szczepanowice, Półwieś, Bierkowice, Wóblin

Region 2 includes the area: Grudzice, Groszowice, Grotowice, raspberry, New Village Royal, Gosławice, Cologne Gosławicka, Zakrzow

The course covers: All the year (summer and winter) cleaning lanes of the city of Opole including: sidewalks, squares, green areas, pedestrian and bicycle and foot-rond (green areas) and subways

Cleaning of sidewalks and pedestrian paths and pedestrian and cycling (collectively "sidewalks") and lawns, city squares, subways, traffic circles (green areas) or the removal of snow, ice, removing roughness by means uszorstniających and specialized equipment, cleaning Ry.

The contract is a framework contract with regard to:

Year-round (summer and winter) cleaning lanes of the city of Opole including: sidewalks, squares, green areas, pedestrian and bicycle and foot-rond (green areas) and subways; Cleaning of sidewalks and pedestrian and bicycle-foot (collectively "sidewalks") and lawns, city squares, subways, traffic circles (green areas) or the removal of snow, ice, removing roughness by means uszorstniających and specialized equipment; Purification of the Market.

The contract is a framework contract with regard to:

Year-round (summer and winter) cleaning lanes of the city of Opole including: sidewalks, squares, green areas, pedestrian and bicycle and foot-rond (green areas) and subways; Cleaning of sidewalks and pedestrian and bicycle-foot (collectively "sidewalks") and lawns, city squares, subways, traffic circles (green areas) or the removal of snow, ice, removing roughness by means uszorstniających and specialized equipment;

Machines and apparatus for testing and measuring

Park Naukowo Technologiczny w Opolu Sp. z o.o. | Published January 14, 2017  -  Deadline February 24, 2017
cpvs
38540000, 42990000, 38424000

The contract is for the purchase and delivery of the system non-contact measurement of machine components for the Science and Technology Park in Opole Sp. z oo within the framework of the project entitled. Cooperative Opole - Professional business environment Detailed description of the equipment contained in the annex to siwz.

Opole: Comprehensive organization of foreign trip to Germany in connection with the organization of the Opole Centre for Economic Development study visit to international companies and institutions successful in the field of business support and participation in the Conference: Forum Aussenwirtschaft Mainz (Forum on Foreign Relations) Project: Cooperative Opole - Professional business environment

Opolskie Centrum Rozwoju Gospodarki | Published September 22, 2016  -  Deadline September 20, 2016
Winner
Sun&More Sp. z o.o., ul. Rapackiego 8c, 71-467 Szczecin, kraj/woj. zachodniopomorskie.
cpvs
55100000, 55300000

3.1 Name of the contract: Comprehensive organization of foreign trip to Germany in connection with the organization of the Opole Centre for Economic Development study visit to international companies and institutions successful in the field of business support and participation in the Conference: Forum Aussenwirtschaft Mainz (Forum on Foreign Relations) Project: cooperative Opole - professional business environment. Object of the contract will be implemented within the framework of the project entitled. Cooperative Opole - Professional business environment co-financed by the European Union under Measure 2.3 Strengthening the business environment from the European Regional Development Fund under the Regional Operational Program of the Opole Province for the years 2014-2020. 3.2 A detailed description of the contract is contained in Annex no. 1A to the Terms of Reference. (Numbering according to the Terms of Reference) ..

Opole: Security services, building and property of the District Court in Głubczyce

Sąd Okręgowy w Opolu | Published August 10, 2016  -  Deadline August 10, 2016
Winner
MASTER SECURITY Sp. z o.o., ul. Śląska 18, 44-206 Rybnik, kraj/woj. śląskie.
cpvs
79710000

1. The contract is to protect people, property and the building of the District Court in Głubczyce Street. Kochanowskiego 1, 48-100 Głubczyce. 2. Specific responsibilities of the Contractor applying for this public procurement contract Appendix 1 hereto. 3. The Contracting Authority requires the employment of the Contractor or subcontractor of any person performing direct physical security of people, property and the building of the District Court in Głubczyce on a contractual basis throughout the duration of the contract. Verification and control of the fulfillment of this requirement and the penalties for failure to comply with this requirement will be implemented by the Employer in accordance with the guidelines contained in the Project Agreement, which constitutes Appendix 3 hereto. 4. The Contracting Authority will provide the Contractor free of adequate social room for officiating protection. 5. Employees performing physical protection in the building of the District Court in Głubczyce Street. Kochanowski 1 during operation of the device for X-ray baggage inspection will be exposed to ionizing radiation (X-rays). 6. Requires the Contractor to perform the object of the contract by persons who have a medical examination allowing to work in an environment exposed to ionizing radiation and confirmations received by these individuals OSH training in radiological protection against ionizing radiation (X-ray).

Opole: Maintenance of watercourses and water management facilities on the main area of ​​operations WZMiUW in Opole Branch in Krapkowice

Wojewódzki Zarząd Melioracji i Urządzeń Wodnych | Published July 21, 2016  -  Deadline September 15, 2016
cpvs
45246400, 45246000

The contract is for the execution of the called Maintenance of watercourses and water management facilities essential in action WZMiUW in Opole Branch in Krapkowice, which includes construction works (m. In. Blowdown, rozplantowanie ore, etc.) for 2 objects (parts) 1. relief River Channel Osobłoga km 0 + 000-1 + 500 2 Sonia km 0 + 000-6 + 000 full scope of works include attached hereto takeoffs. NOTES: 1. Desired by the principal to the contractor prior to issuing tenders acquainted with Part III of the Terms of Reference and made inspection of the place of performance of the contract (agreement with the competent manager WZMiUW in Opole), to take account of the specific nature of the price of its offer. This provision should be understood that in every place in the Terms of Reference, which uses the names, the following words or equivalent. 3. It is recognized that the offer is equivalent to that which represents the subject of the order of the functional properties and quality of the same or similar to those circled in this Terms of Reference, but marked another trademark, patent or origin. In this case, the Contractor is obliged to repair the damage wielding terrain without undue delay, or by restoring the land to its original state, or by the payment of an appropriate sum of money. 5. The Contractor shall take all reasonable steps to protect the environment both on the Site, and beyond, and to limit damage and nuisance to people and property resulting from pollution, noise and other effects of his actions. All fees and penalties for exceeding during the works standards referred to in the relevant regulations concerning environmental protection, borne by the Contractor. 7. The Contractor shall pay the relevant fees and obtain at its own expense all arrangements and export licenses for solid and liquid waste and waste, and safe, proper drainage of groundwater and rainwater from around the Site, or sites related to the conduct of the Works, so that neither Robots or the environment are not damaged. The Contractor shall, at his own risk and cost, provide all equipment necessary for your use of these services and to measure the amount collected 9. Before Works Contractor is obliged to provide written notice of all interested parties (owners or administrators areas, owners of devices and existing underground utilities ) on the date of commencement of the Works and the expected date of completion of the Works. 10. The contractor will limit its activities to the area covered by the robots utrzymaniowymi Contractor shall take the necessary steps to maintain the Contractor's Equipment and Contractor's Personnel within the Site and these additional areas, away from the neighboring areas. The contractor will remove from the Site any wreckage, rubbish and temporary infrastructure, which are no longer needed. Each waste must be handled in accordance with applicable law and in agreement with the Employer. Carried out photographic documentation of the Contractor shall provide the Employer. 14. The contractor is familiar with the location of all existing installations, such as dehydration, lines and telephone poles and electrical, fiber, water supply, gas pipelines and the like, before starting any excavation or other operations that could damage the existing installations. 15. Each time prior to earthworks, checking excavations will be made to identify underground installations where damage could endanger traffic safety. Contractor shall immediately repair any resulting damage at his own expense and, if necessary, carry out other work ordered by the competent department WZMiUW in Opole. 17. The contractor will be required to obtain all necessary consents and permits local authorities, businesses and owners required to remove the existing installation necessary, install temporary installations, remove the temporary installation and re-installation of existing installations, each time on the basis of agreements made with the customer. 18. The Contractor shall ensure that the Works will be guided by individuals with relevant experience and education.

Opole: Recognition of nature and to act natural supervision during the implementation of works on maintenance of water and water facilities in selected streams in the province of Opole

Wojewódzki Zarząd Melioracji i Urządzeń Wodnych | Published July 19, 2016  -  Deadline July 18, 2016
Winner
PLECOTUS Alicja Żołnowska, Miejsce ul. Parkowa 4b, 46-112 Świerczów, kraj/woj. opolskie.
cpvs
90713000, 71313000

The contract is to recognize the natural in front of accessions to the raccoon scope of the maintenance of water and water facilities, and when it is due to the decision of the Regional Director for Environmental Protection, perform environmental supervision during the execution of works on the maintenance of water in environmentally valuable areas in terms of compliance with the Act April 16, 2004. Nature Conservation (Dz. U. of 2013., pos. 627, as amended.), the Act of 27 April 2001. Environmental Protection Law (Dz. U. of 2013. Item. 1232, as amended.), And to respect and implement the recommendations consistent with the Decisions of the Regional Director for Environmental Protection in Opole and in accordance with applicable regulations. 1. Identification of nature is to confirm or exclude the presence on designated sections of watercourses, for maintenance works, plant or animal species under strict or partial protection of species occurring in the database of the Regional Directorate for Environmental Protection in Opole and determine the impact of these works on existing organisms protected and their habitat. From conducted reconnaissance Contractor is obliged to submit a report to the Investor of the actions performed. 2. Supervision nature will take place only on sections of rivers on which the Regional Directorate of Environmental Protection in Opole issued a decision in this regard and is to be executed in accordance with the recommendations set out in these decisions. Supervision is to control where and how to carry out maintenance works on devices of basic water management in order to minimize the negative effects of these works on the environment, including the impact of a potentially occurring within and the immediate vicinity of the work species of flora and fauna protected species, and present habitats to be protected. An integral part of the terms of reference is annexed Excel List price supervision natural ..

Opole: Maintenance of watercourses and water management facilities on the main area of ​​operations WZMiUW in Opole Branch in Krapkowice

 | Published July 13, 2016  -  Deadline November 15, 2016
cpvs
45246400, 45246000

The contract is for the execution of the called Maintenance of watercourses and water management facilities essential in action WZMiUW in Opole Branch in Krapkowice, which includes construction works (m. In. Desludging, deleting namułu, etc.) for the 5 objects (parts) 1. River Jemielnica km 25 + 400 -52 + 050 size: 26650 m 2 River Koźlanka km 0 + 000 - 8 + 400 size 8400 mb 3. River Ligocki Koźle km 0 + 000 - 12 + 490 size: 12490 mb 4 . the river valley km 0 + 000 - 11 + 700 size: 11700 m 5. River Piotrówka km 0 + 000 - 9 + 500 size: 9500 m the full scope of works include attached hereto takeoffs. NOTES: 1. Desired by the principal to the contractor prior to issuing tenders acquainted with Part III of the Terms of Reference and made inspection of the place of performance of the contract (agreement with the competent manager WZMiUW in Opole), to take account of the specific nature of the price of its offer. This provision should be understood that in every place in the Terms of Reference, which uses the names, the following words or equivalent. 3. It is recognized that the offer is equivalent to that which represents the subject of the order of the functional properties and quality of the same or similar to those circled in this Terms of Reference, but marked another trademark, patent or origin. In this case, the Contractor is obliged to repair the damage wielding terrain without undue delay, or by restoring the land to its original state, or by the payment of an appropriate sum of money. 5. The Contractor shall take all reasonable steps to protect the environment both on the Site, and beyond, and to limit damage and nuisance to people and property resulting from pollution, noise and other effects of his actions. All fees and penalties for exceeding during the works standards referred to in the relevant regulations concerning environmental protection, borne by the Contractor. 7. The Contractor shall pay the relevant fees and obtain at its own expense all arrangements and export licenses for solid and liquid waste and waste, and safe, proper drainage of groundwater and rainwater from around the Site, or sites related to the conduct of the Works, so that neither Robots or the environment are not damaged. The Contractor shall, at his own risk and cost, provide all equipment necessary for your use of these services and to measure the amount collected 9. Before Works Contractor is obliged to provide written notice of all interested parties (owners or administrators areas, owners of devices and existing underground utilities ) on the date of commencement of the Works and the expected date of completion of the Works. 10. The contractor will limit its activities to the area covered by the robots utrzymaniowymi Contractor shall take the necessary steps to maintain the Contractor's Equipment and Contractor's Personnel within the Site and these additional areas, away from the neighboring areas. The contractor will remove from the Site any wreckage, rubbish and temporary infrastructure, which are no longer needed. Each waste must be handled in accordance with applicable law and in agreement with the Employer. Carried out photographic documentation of the Contractor shall provide the Employer. 14. The contractor is familiar with the location of all existing installations, such as dehydration, lines and telephone poles and electrical, fiber, water supply, gas pipelines and the like, before starting any excavation or other operations that could damage the existing installations. 15. Each time prior to earthworks, checking excavations will be made to identify underground installations where damage could endanger traffic safety. Contractor shall immediately repair any resulting damage at his own expense and, if necessary, carry out other work ordered by the competent department WZMiUW in Opole. 17. The contractor will be required to obtain all necessary consents and permits local authorities, businesses and owners required to remove the existing installation necessary, install temporary installations, remove the temporary installation and re-installation of existing installations, each time on the basis of agreements made with the customer. 18. The Contractor shall ensure that the Works will be guided by individuals with relevant experience and education.

Opole: Security services, building and property of the District Court in Głubczyce

 | Published July 11, 2016  -  Deadline December 31, 2017
cpvs
79710000

1. The contract is to protect people, property and the building of the District Court in Głubczyce Street. Kochanowskiego 1, 48-100 Głubczyce. 2. Specific responsibilities of the Contractor applying for this public procurement contract Appendix 1 hereto. 3. The Contracting Authority requires the employment of the Contractor or subcontractor of any person performing direct physical security of people, property and the building of the District Court in Głubczyce on a contractual basis throughout the duration of the contract. Verification and control of the fulfillment of this requirement and the penalties for failure to comply with this requirement will be implemented by the Employer in accordance with the guidelines contained in the Project Agreement, which constitutes Appendix 3 hereto. 4. The Contracting Authority will provide the Contractor free of adequate social room for officiating protection. 5. Employees performing physical protection in the building of the District Court in Głubczyce Street. Kochanowski 1 during operation of the device for X-ray baggage inspection will be exposed to ionizing radiation (X-rays). 6. Requires the Contractor to perform the object of the contract by persons who have a medical examination allowing to work in an environment exposed to ionizing radiation and confirmations received by these individuals OSH training in radiological protection against ionizing radiation (X-ray).

Opole: Maintenance of watercourses and water management facilities on the main area of ​​operations WZMiUW in Opole Branch Oleśno

Wojewódzki Zarząd Melioracji i Urządzeń Wodnych | Published July 20, 2016  -  Deadline December 15, 2016
cpvs
45246400, 45246000

The contract is for the execution of the called Maintenance of watercourses and water management facilities essential in action WZMiUW in Opole Branch Oleśno, which includes construction works (m. In. Blowdown, rozplantowanie ore, etc.) for 8 objects (parts) 1. River Borecki km 0 + 000-18 + 150 2. River Julianpolka II km 8 + 470-14 + 194 3. From River Bzionkowa km 0 + 000-7 + 200 4. River Pawłowiczanka km 0 + 000-2 + 760 5. current River III km 5 + 314-10 + 317 6. River Sowczycki I 0 + 000-2 + ​​600 7. River Sowczycki II 4 + 006-12 + 045 8. Old River Prosna 0 + 000-2 + ​​745 the full scope of works include attached hereto takeoffs. NOTES: 1. Desired by the principal to the contractor prior to issuing tenders acquainted with Part III of the Terms of Reference and made inspection of the place of performance of the contract (agreement with the competent manager WZMiUW in Opole), to take account of the specific nature of the price of its offer. This provision should be understood that in every place in the Terms of Reference, which uses the names, the following words or equivalent. 3. It is recognized that the offer is equivalent to that which represents the subject of the order of the functional properties and quality of the same or similar to those circled in this Terms of Reference, but marked another trademark, patent or origin. In this case, the Contractor is obliged to repair the damage wielding terrain without undue delay, or by restoring the land to its original state, or by the payment of an appropriate sum of money. 5. The Contractor shall take all reasonable steps to protect the environment both on the Site, and beyond, and to limit damage and nuisance to people and property resulting from pollution, noise and other effects of his actions. All fees and penalties for exceeding during the works standards referred to in the relevant regulations concerning environmental protection, borne by the Contractor. 7. The Contractor shall pay the relevant fees and obtain at its own expense all arrangements and export licenses for solid and liquid waste and waste, and safe, proper drainage of groundwater and rainwater from around the Site, or sites related to the conduct of the Works, so that neither Robots or the environment are not damaged. The Contractor shall, at his own risk and cost, provide all equipment necessary for your use of these services and to measure the amount collected 9. Before Works Contractor is obliged to provide written notice of all interested parties (owners or administrators areas, owners of devices and existing underground utilities ) on the date of commencement of the Works and the expected date of completion of the Works. 10. The contractor will limit its activities to the area covered by the robots utrzymaniowymi Contractor shall take the necessary steps to maintain the Contractor's Equipment and Contractor's Personnel within the Site and these additional areas, away from the neighboring areas. The contractor will remove from the Site any wreckage, rubbish and temporary infrastructure, which are no longer needed. Each waste must be handled in accordance with applicable law and in agreement with the Employer. Carried out photographic documentation of the Contractor shall provide the Employer. 14. The contractor is familiar with the location of all existing installations, such as dehydration, lines and telephone poles and electrical, fiber, water supply, gas pipelines and the like, before starting any excavation or other operations that could damage the existing installations. 15. Each time prior to earthworks, checking excavations will be made to identify underground installations where damage could endanger traffic safety. Contractor shall immediately repair any resulting damage at his own expense and, if necessary, carry out other work ordered by the competent department WZMiUW in Opole. 17. The contractor will be required to obtain all necessary consents and permits local authorities, businesses and owners required to remove the existing installation necessary, install temporary installations, remove the temporary installation and re-installation of existing installations, each time on the basis of agreements made with the customer. 18. The Contractor shall ensure that the Works will be guided by individuals with relevant experience and education.

Opole: Repair of the dam, located at km 44 + 442 River Ścinawa Niemodlin, in m. Rynarcice

Wojewódzki Zarząd Melioracji i Urządzeń Wodnych | Published July 20, 2016  -  Deadline July 19, 2016
Winner
Zakład Budownictwa Ogólnego i Inżynierii Wodnej Stanisław Łojko, ul. Chrobrego 8, 48-340 Głuchołazy, kraj/woj. opolskie.
cpvs
45246400, 45246000

The contract is for the execution of the called Repair weir located at km 44 + 442 River Ścinawa Niemodlin, in m. Repaired both abutments of the weir by forging the outer surface of the concrete, giving back seats rotten concrete, sealing and eliminate the cracks as well as the execution of coats repair the bridge concrete weir by forging the outer surface of the concrete, giving back seats rotten concrete, sealing and eliminate the cracks as well as the execution of protective coats of reinforced concrete, anchored in Cleaning and corrosion protection for steel railings footbridge weir 4. Restoring security boundary in front of the left and right foothold weir of WG on length of about 15 m , the precise scope of work required to perform included NOTES: 1) the Contractor prior to issuing tenders should make inspection of the place of performance of the contract to take into account the specificity In this case, the Contractor is obliged to repair the damage wielding terrain without undue delay, or by restoring the land to its original state or 3) the Contractor shall take all reasonable steps to protect the environment both on the site and beyond, and to limit damage and 4) the Contractor is obliged to know and used during the execution of works, all provisions relating to the protection all fees and penalties for exceeding the during the execution of works standards referred to in the relevant regulations concerning the protection 5) the Contractor shall pay the relevant fees and obtain at its own expense all arrangements and export licenses for solid and liquid waste and waste, and safe, proper drainage of groundwater and rainwater from the entire construction site, or places associated with running 6) the Contractor shall be responsible for the supply of energy, water and other services they may need for the execution of works covered When using the supply of energy, water and other services from existing controlled sources, the Contractor must comply with the conditions presented to him by the competent authority and the contractor, at his own risk and cost, provide all equipment necessary for your use of these services and for measuring the collected amount of 7) during the execution of works the contractor will keep the site free from any unnecessary obstacles and can store or rid any avoidable Equipment the Contractor shall remove from the site any wreckage, rubbish and 8) the contractor on the construction site will be every waste must be handled in accordance with applicable law and 9) to document bring the Site and Works to its original condition Contractor shall maintain detailed records photographic covering state Terrain carried out photographic documentation of 10) Each time prior to earthworks, checking excavations will be made to identify underground installation, which damaged 11) the Contractor shall be responsible for any damage to roads, drainage ditches, water and gas pipes, poles and power lines , cables, points of geodetic and installation of any kind caused by him during the Contractor shall immediately repair any resulting damage at his own expense, as well as, 12) Robots are covered by warranty period and the warranty starts from the date of the contract and recognition by the Employer as duly made, the warranty period the contractor and warranty for this task Guarantee and warranty in case of cancellation after completing 13) the contractor shall submit at the end of

Cleaning services

Szpital Wojewódzki w Opolu Sp. z o.o. | Published April 28, 2016
Winner
Konsorcjum firm: DGP Clean Prtner Sp. z o.o.
cpvs
90910000

Performing services related to the maintenance of cleanliness and performance of sanitary treatment of the Employer, in accordance with the sanitary-epidemiological assistance in patient care, help with the feeding of patients, management of underwear hospital and perform cleanup work, transport, and services in the field of waste management and hygiene environment.

Sewage, refuse, cleaning and environmental services

Miasto Opole | Published April 2, 2016  -  Deadline April 25, 2016
cpvs
90000000, 90512000

Sewage, refuse, cleaning / cleaning and environmental services

Sewage, refuse, cleaning and environmental services

Miasto Opole | Published May 21, 2016
Winner
Przedsiębiorstwo Usługowo-Handlowe „ANN-POL”
cpvs
90000000, 90512000

1.1. The contract is for summer cleaning lanes of the city of Opole in the years 2016-2017, including: sidewalks, squares, green areas, pedestrian and bicycle and foot-rond (green areas) and subways

1.2. Complex tasks covered by the contract is the fulfillment of the obligations related

the maintenance of cleanliness and order on public roads within the administrative limits of the city of Opole imposed on the Purchaser in accordance with the Act of 1 July 2011 amending the Act on maintaining cleanliness and order in municipalities (Dz. U. 2011. No. 152, item. 897 No. 171, item. 1016 No. 224, item. 1337).

1.3. Object of the contract includes the following tasks:

- Cleaning of sidewalks, squares, green areas, pedestrian and bicycle and foot-rond (green areas) and go underground with sand, debris and other contaminants municipal

- The removal of contaminants from roadsides, green belts and roadside ditches with wygrabieniem and export of fallen leaves;

1.4. According to the a / m Act dim. in paragraph. 1.3. tasks of cleaning services covered by the contract does not include:

- Clean-up of pollution from the sidewalks along the property (although for the pavement is considered a separate part of the public road serving for pedestrians located directly on the border of the property), in which case it is the task of the owner of the adjacent real estate (with the exception of the pavement, which is approved paid stop or parking of vehicles);

- Area road lane constituting the construction site - in which case this obligation rests with the construction manager.

Sewage, refuse, cleaning and environmental services

Miasto Opole | Published May 21, 2016  -  Deadline June 8, 2016
cpvs
90000000, 90512000

Sewage, refuse, cleaning / cleaning and environmental services

Opole: Maintenance of watercourses and water management facilities on the main area of ​​operations WZMiUW in Opole Branch in Krapkowice

Wojewódzki Zarząd Melioracji i Urządzeń Wodnych | Published July 22, 2016  -  Deadline October 15, 2016
cpvs
45246400, 45246000

The contract is for the execution of the called Maintenance of watercourses and water management facilities essential in action WZMiUW in Opole Branch in Krapkowice, which includes construction works (m. In. Excavations, rozplantowanie ore, etc.) on the object River Osobłoga in km 0 + 000-14 + 700. The full scope of works includes attached hereto Takeoff. NOTES: 1. Desired by the principal to the contractor prior to issuing tenders acquainted with Part III of the Terms of Reference and made inspection of the place of performance of the contract (agreement with the competent manager WZMiUW in Opole), to take account of the specific nature of the price of its offer. This provision should be understood that in every place in the Terms of Reference, which uses the names, the following words or equivalent. 3. It is recognized that the offer is equivalent to that which represents the subject of the order of the functional properties and quality of the same or similar to those circled in this Terms of Reference, but marked another trademark, patent or origin. In this case, the Contractor is obliged to repair the damage wielding terrain without undue delay, or by restoring the land to its original state, or by the payment of an appropriate sum of money. 5. The Contractor shall take all reasonable steps to protect the environment both on the Site, and beyond, and to limit damage and nuisance to people and property resulting from pollution, noise and other effects of his actions. All fees and penalties for exceeding during the works standards referred to in the relevant regulations concerning environmental protection, borne by the Contractor. 7. The Contractor shall pay the relevant fees and obtain at its own expense all arrangements and export licenses for solid and liquid waste and waste, and safe, proper drainage of groundwater and rainwater from around the Site, or sites related to the conduct of the Works, so that neither Robots or the environment are not damaged. The Contractor shall, at his own risk and cost, provide all equipment necessary for your use of these services and to measure the amount collected 9. Before Works Contractor is obliged to provide written notice of all interested parties (owners or administrators areas, owners of devices and existing underground utilities ) on the date of commencement of the Works and the expected date of completion of the Works. 10. The contractor will limit its activities to the area covered by the robots utrzymaniowymi Contractor shall take the necessary steps to maintain the Contractor's Equipment and Contractor's Personnel within the Site and these additional areas, away from the neighboring areas. The contractor will remove from the Site any wreckage, rubbish and temporary infrastructure, which are no longer needed. Each waste must be handled in accordance with applicable law and in agreement with the Employer. Carried out photographic documentation of the Contractor shall provide the Employer. 14. The contractor is familiar with the location of all existing installations, such as dehydration, lines and telephone poles and electrical, fiber, water supply, gas pipelines and the like, before starting any excavation or other operations that could damage the existing installations. 15. Each time prior to earthworks, checking excavations will be made to identify underground installations where damage could endanger traffic safety. Contractor shall immediately repair any resulting damage at his own expense and, if necessary, carry out other work ordered by the competent department WZMiUW in Opole. 17. The contractor will be required to obtain all necessary consents and permits local authorities, businesses and owners required to remove the existing installation necessary, install temporary installations, remove the temporary installation and re-installation of existing installations, each time on the basis of agreements made with the customer. 18. The Contractor shall ensure that the Works will be guided by individuals with relevant experience and education.

Opole: Comprehensive organization of foreign trip to Germany in connection with the organization of the Opole Centre for Economic Development study visit to international companies and institutions successful in the field of business support and participation in the Conference: Forum Aussenwirtschaft Mainz (Forum on Foreign Relations) Project: Cooperative Opole - Professional business environment

Opolskie Centrum Rozwoju Gospodarki | Published July 22, 2016  -  Deadline November 30, 2016
cpvs
55100000, 55300000

3.1 Name of the contract: Comprehensive organization of foreign trip to Germany in connection with the organization of the Opole Centre for Economic Development study visit to international companies and institutions successful in the field of business support and participation in the Conference: Forum Aussenwirtschaft Mainz (Forum on Foreign Relations) Project: cooperative Opole - professional business environment. Object of the contract will be implemented within the framework of the project entitled. Cooperative Opole - Professional business environment co-financed by the European Union under Measure 2.3 Strengthening the business environment from the European Regional Development Fund under the Regional Operational Program of the Opole Province for the years 2014-2020. 3.2 A detailed description of the contract is contained in Annex no. 1A to the Terms of Reference. (Numbering according to the Terms of Reference).

Sewage, refuse, cleaning and environmental services

Miasto Opole | Published January 5, 2016
Winner
Remondis Opole Sp. z o.o.
cpvs
90000000, 90512000, 34928480

The tasks in the field of maintenance of the above: a) emptying street baskets owned DGP in Opole; b) emptying street baskets and leasing owned by the Contractor; c) emptying and leasing of containers of 240 liters. owned by the Contractor; d) emptying and leasing 1100 liter containers. owned by the Contractor; e) set the new or transferring used baskets street from the original location in the place indicated by the Employer (regardless of the type of trash).

Sewage, refuse, cleaning and environmental services

Miasto Opole | Published March 10, 2016  -  Deadline April 6, 2016
cpvs
90000000, 90512000

Sewage, refuse, cleaning / cleaning and environmental services

Implementation of digital documentation of the network infrastructure with the introduction of data to the simulation environment and services for research carried out under the Applied Research Project funded by the NCBiR in Warsaw.

Politechnika Opolska | Published March 8, 2016
Winner
Marek Gazda Envi Konsulting
cpvs
48000000

Requirements for warranty service:

a) The Contractor agrees to bear all costs associated with warranty service, which includes the period from the signing of the contract for completion of the project.

b) The Contractor agrees to remove.

Engineering design services for the construction of civil engineering works

Zarząd Dróg Wojewódzkich w Opolu | Published January 2, 2016
Winner
Pracownia Projektowa PROKOM mgr inż. Kazimierz Kurowski
cpvs
71322000

1. The contract is for the construction and project development executive for the project "Development of the provincial road No. 409 on the section Rożniątów - Strzelce Opole at km 40 + 100 - 42 + 813 broken down into tasks A and B" under the terms of the terms of reference. Code and name of the Common Procurement Vocabulary: 71.32.20.00-1 - Engineering design services in the field of civil engineering. 2. Subject of the contract includes: a) surveying: - the division of plots - 130 parcels - to develop maps for design purposes, b) the design work - construction projects and obtaining two decisions authorizing the investment road - executive projects - Projects traffic organization - target - plans for health and safety BIOZ - detailed technical specifications for performance and acceptance of works - some estimates (investment estimate, cost estimate, bill of quantities, calculation of unit prices) - information card about sharing information about the environment and its protection, public participation in environmental protection and environmental impact assessment - shared tasks A and B, - environmental impact report - common for tasks A and B, - materials for application for a decision on the environmental permit for the project along obtaining a decision shared tasks A and B - operaty water law with obtaining permits water legislation - separate for tasks A and B, - the study of land-drilling (33 pcs. by a list of parameters perform geological drilling), - research capacity of the surface by deflections (5.426 km - 2 lanes), - other elements necessary for the job.